Terms & Conditions

Welcome to Nilkanth Equipments. By accessing our website, requesting quotations, purchasing products, or using our services, you agree to be bound by the following Terms & Conditions.

Please read these terms carefully before using our website or engaging with our services.

About Nilkanth Equipments

Nilkanth Equipments is a supplier of commercial kitchen equipment, hotel kitchen equipment, bakery equipment, refrigeration systems, stainless steel furniture, crockery, utensils, and turnkey kitchen solutions for restaurants, hotels, cafés, cloud kitchens, caterers, and institutional kitchens.

Acceptance of Terms

By using our website, submitting enquiries, requesting quotations, or purchasing products, you agree to comply with these Terms & Conditions and all applicable laws and regulations.

If you do not agree with any part of these terms, please refrain from using our website and services.

Product Information

We strive to provide accurate descriptions, specifications, and images of our commercial kitchen equipment and related products.

However:

• Product images are for illustration purposes only.
• Actual product appearance may vary.
• Specifications may change without prior notice.
• Product availability is subject to stock and supplier availability.

Nilkanth Equipments reserves the right to update product information at any time.

Quotations and Pricing

All quotations provided by Nilkanth Equipments are subject to:

• Product availability
• Applicable taxes
• Transportation charges
• Installation requirements
• Changes in market prices

Prices are subject to change without prior notice unless specifically confirmed in writing.

Quotation validity may vary depending on the project and product category.

Orders and Payments

Orders will be processed only after confirmation and receipt of the agreed payment amount.

Customers are responsible for providing accurate billing, delivery, and project information.

Nilkanth Equipments reserves the right to cancel or refuse any order if incorrect information, pricing errors, or unforeseen circumstances arise.

Delivery and Installation

Delivery timelines provided are estimated and may vary due to:

• Product availability
• Transportation delays
• Weather conditions
• Supplier-related delays
• Site readiness issues

While we make every effort to deliver products on time, Nilkanth Equipments shall not be held liable for delays beyond our reasonable control.

Installation services, where applicable, will be scheduled based on project requirements and site conditions.

Warranty

Certain commercial kitchen equipment products may be covered under manufacturer warranties.

Warranty coverage, duration, and terms vary by product and manufacturer.

Warranty does not cover:

• Improper usage
• Unauthorized modifications
• Negligence
• Physical damage
• Electrical fluctuations
• Lack of maintenance

Customers should refer to the specific warranty terms provided with the product.

Returns and Replacements

Returns and replacements may be accepted only under approved circumstances, including:

• Manufacturing defects
• Wrong product delivery
• Products damaged during transportation

Customers must notify Nilkanth Equipments within a reasonable period after receiving the product.

Custom-made, special-order, and project-based equipment may not be eligible for return unless otherwise agreed in writing.

Customer Responsibilities

Customers agree to:

• Provide accurate information
• Ensure site readiness before installation
• Follow product operating instructions
• Use equipment safely and responsibly
• Comply with applicable safety standards

Failure to follow these responsibilities may affect warranty eligibility and service support.

Intellectual Property

All content on this website, including text, logos, graphics, images, product descriptions, and design elements, is the property of Nilkanth Equipments unless otherwise stated.

No content may be copied, reproduced, distributed, or used without prior written permission.

Website Usage

Users agree not to:

• Use the website for unlawful purposes
• Attempt unauthorized access to website systems
• Distribute harmful software or malicious code
• Interfere with website functionality

Nilkanth Equipments reserves the right to restrict access to users who violate these terms.

Limitation of Liability

Nilkanth Equipments shall not be liable for any indirect, incidental, special, or consequential damages arising from:

• Website usage
• Product delays
• Business interruptions
• Loss of profits
• Third-party actions

Our maximum liability shall not exceed the value of the purchased product or service.

Third-Party Links

Our website may contain links to third-party websites for additional information or convenience.

We do not control or endorse third-party websites and are not responsible for their content, privacy practices, or services.

Privacy

Your use of our website is also governed by our Privacy Policy, which explains how we collect, use, and protect your personal information.

Changes to Terms & Conditions

Nilkanth Equipments reserves the right to modify these Terms & Conditions at any time without prior notice.

Updated terms will be posted on this page and become effective immediately upon publication.

Governing Law

These Terms & Conditions shall be governed by and interpreted in accordance with the laws of India.

Any disputes arising from these terms shall be subject to the jurisdiction of the courts of Ahmedabad, Gujarat.